Image

Call us:

360-776-7368

Image

Active in:

8112 198th Ave Ct E

Terms & Conditions

Services Provided

We provide professional electrical services, including but not limited to electrical panel upgrades, breaker and fuse box replacements, electrical repairs, lighting installation, outlet and switch installation, and related residential and light commercial electrical work. The specific scope of services will be detailed in your service agreement, work order, or booking confirmation.

1. Booking and Payment

Estimates:
All quotes or estimates provided are valid for 30 days unless otherwise specified.

Payment Terms:
Payments are due upon completion of services unless otherwise agreed in writing. We accept [list accepted payment methods, e.g., cash, credit/debit card, etc.].

Cancellations:
Appointments must be canceled at least 24 hours in advance. Late cancellations or missed appointments may incur a fee.

2. Customer Responsibilities

You agree to:

- Provide accurate information about your service needs.

- Ensure clear and safe access to your electrical panel, meter, and other work areas.

- Secure pets and keep the workspace safe and free from hazards.

- Obtain any required permissions from your landlord, HOA, or property manager, if applicable.

3. Limitations of Liability

We are not liable for:

- Any indirect, incidental, or consequential damages resulting from the use of our services.

- Delays caused by factors beyond our control, including weather, utility company issues, supplier delays, or customer-related delays.

Our maximum liability is limited to the amount paid for the specific service provided

4. Intellectual Property

All content on our website, including text, images, logos, and branding, is the property of Mutual Electric NW (or used with permission). You may not reproduce, distribute, or use any content without our prior written consent.

5. Termination

We reserve the right to terminate or refuse service at our discretion, including in cases of unsafe working conditions, violations of these Terms and Conditions, or suspected illegal activity.

6. Governing Law

These Terms are governed by the laws of the State of Washington. Any disputes will be resolved exclusively in the courts located within Washington State.


7. Changes to Terms

We reserve the right to update these Terms at any time. Changes will be posted on this page, and your continued use of the website or services constitutes acceptance of the updated Terms.

For questions or concerns about these Terms, contact us at:
Email: [email protected]
Phone: 360-776-7368

Image

Call us:

360-776-7368

Image

Active in:

8112 198th Ave Ct E

© copyright 2025 All Rights Reserved. Powered & by Lanello